Originally published by Matthew DeVries on Best Practices Construction Law blog.
In County of Galveston v. Triple B Services, LLP, decided on May 26, 2016, the Court of Appeals of Texas reviewed a contractor’s claim for damages on a road expansion project. While the legal issue focused on the County’s right rely on the defense of sovereign immunity, the Contractor’s (and it expert’s) characterization of the damages was critical to the outcome of the case. Since the applicable statute waives a county’s sovereign immunity for breach-of-contract damages that are “a direct result of owner-caused delays,” the Court had to decide whether disruption damages — as opposed to delay damages — were recoverable.
Although the project in this case was finished on time and the Contractor never completely “stopped” its work, the Court readily found that the Contractor was “hindered” because of the County’s actions. Since the type of recoverable damages include those that are “a direct result of owner-caused delays,” the Contractor could recover its disruption damages.